Terms and Conditions

 

    Sligo Glass Company Ltd. Terms & Conditions for the Supply of Goods and Services to Consumers.

 

    The customer’s attention is drawn in particular to the provisions of clause 8.

 

1. INTERPRETATION
The definitions in this clause apply in the terms and conditions set out in this document: Goods: the products that we are selling to you as set out in the Order. Installation Services: the installation services as detailed overleaf which you agree to purchase from us. Order: your order for the Goods and/or Installation Services as set out overleaf. Order Confirmation: shall have the meaning set out in clause 2.4. Price: is as defined in clause 9.1 of these Terms. Terms: the terms and conditions set out in this document and any special or additional terms and conditions agreed in writing by the company and recorded overleaf. We, us or our: Sligo Glass Company Ltd. (Co No. 65829) whose registered address is Finisklin Road, Sligo, Co. Sligo, Writing or written includes e-mail. 1.2 Headings do not affect the interpretation of these terms.

2. OUR CONTRACT WITH YOU
2.1 (a) These are the terms and conditions on which we supply the Goods and or Installation Services to you; (b) Please ensure that you read these Terms carefully, and check that the details on the Order are complete and accurate, before you sign the Order. If you think that there is a mistake, please contact us to discuss, and please make sure that you ask us to confirm any changes in writing to avoid any confusion between you and us. (c) We consider that these Terms and the Order constitute the whole agreement between you and us.
2.2 Any samples, drawings, or advertising we issue, and any illustrations contained in our catalogues or brochures, are produced solely to provide you with an approximate idea of the Goods they describe. The units specified on the Order will be manufactured according to the published specification, but pursuant to our policy of continuous improvements to our products, we must reserve the right to modify such specifications from time to time.
2.3 We may need to make changes to the specification of the Goods if required to conform to any applicable safety or other statutory requirements.
2.4 The Order is an offer by you to enter into a binding contract, which we are free to accept or decline at our absolute discretion.
2.5 These Terms shall become binding on you and us when we issue you with written acceptance of an Order at which point a contract shall come into existence between us.
2.6 You may at any time before any agreed delivery or installation date amend or cancel an Order by providing us with written notice. If you amend or cancel an Order, your liability to us shall be limited to payment to us of all costs (including any agreed to waive your rights to cancel in this 7 working day period) we reasonably incur in fulfilling the Order until we receive your amendment or cancellation, except that where the amendment or cancellation results from our failure to comply with these Terms you shall have no liability to us for it.
2.7 We have the right to revise and amend these Terms from time to time. You will be subject to the policies and terms in force at the time that you order the Goods from us, unless any change to those policies or these Terms is required by law or government or regulatory authority (in which case, it will apply to orders you have previously placed that we have not yet fulfilled).

3. THE GOODS
3.1 We warrant that on delivery the Goods shall: (a) conform in all material respects with their description; (b) be of satisfactory quality; (c) be fit for any purpose we say the Goods are fit for or for any reasonable purpose for which you use the Goods; (d) be free from material defects in design, material and workmanship (please note that we cannot accept liability for imperfections of a minor or insignificant nature; (e) comply with all applicable statutory and regulatory requirements.
3.2 This warranty does not apply to any defect in the Goods arising from fair wear and tear, wilful damage, accident, negligence by you or any third party, if you use the Goods in a way that we do not recommend, your failure to follow our instructions, or any alteration or repair you carry out without our prior written approval.
3.3 We will take reasonable steps to protect the Goods properly and to ensure that you receive your order in good condition.
3.4 These Terms apply to any repaired or replacement Goods we supply to you in the unlikely event that the original Goods are faulty or do not otherwise conform to these Terms.

4. DEFECTIVE GOODS AND RETURNS
4.1 In the unlikely event that the Goods do not conform to these Terms, please let us know as soon as possible after delivery. We will check whether the Goods are faulty and if so we will: (a) provide you with a full or partial refund; or (b) replace the Goods; or (c) repair the Goods.
4.2 If any due payment is outstanding we may refuse to carry out remedial works (including any guarantee provisions) where reasonable.
5. DELIVERY
5.1 Delivery and/or installation dates suggested and marked overleaf are estimates only and subject to our written/ verbal confirmation. Whilst we will use reasonable endeavours to effect
delivery and complete installation by estimated dates, you shall not be entitled to terminate this contract by reason only of our failure to effect delivery or complete installation by the estimated dates.
5.2 We will endeavour to meet the estimated time-frame for delivery and installation. In the event of delays in completing works, you will be kept informed. If there are any special circumstances which make the estimated completion date particularly important, these should be notified to us in writing prior to you placing the Order.

6. INSTALLATION
6.1 We will carry out only the Installation Services shown overleaf.
6.2 You will permit us (and our agents, employees and contractors) access to the installation site at all reasonable times so that we may complete the installation between the hours of 8.00am and 5.00pm.
6.3 Neither us nor our agents (employees or contractors) will be responsible for any structural defects or underground obstructions existing in the installation site at the time of commencement of the works and which become evident as the Installation Services progress.
6.4 We cannot accept liability for imperfections of a minor or insignificant nature.
6.5 We will rectify any damage to plastering caused during installation to the areas close (in our reasonable opinion) to the items being replaced, but we cannot undertake to match exact finishes such as external rendering.
6.6 We will take the utmost care when removing windows and doors where tiling has been fitted up to the windows and doors, but can take no responsibility or accept any liability for damaged tiles which break under flexing when removing windows and doors as it is almost certain that tiles will break in this situation.
6.7 It is your responsibility to remove and replace curtains, blinds and pelmets. We will not be required to remove existing fittings and materials so that they may be capable of re-use. It is not possible to ensure an exact match to existing brickwork due to manufacturing processes; however we will use reasonable endeavours to obtain as close a match as possible.
6.8 We are unable to guarantee that condensation will be eliminated following installation and give no warranty in this regard.
6.9 We are not permitted to move telephone cables and junction boxes attached to existing window frames it is your responsibility to arrange with your telephone provider for the relocation of these, either before or during installation. 6.10 It is your responsibility to ensure that any alarm systems attached to doors or windows which are to be replaced are disconnected before installation (and replaced and connected following installation).

7. APPROVALS
7.1 Unless otherwise agreed it is your responsibility to obtain all relevant and necessary approvals, including but not limited to any deed of covenant or landlord approval and/or those from local authorities in respect of building regulations, planning permission, alterations to listed buildings or alterations carried out in a conservation area. We cannot be held responsible for any delay in completion of the contract, or other loss directly arising from your failure or delay in obtaining any of the above. Any costs associated with taking down or removing an installation in these circumstances will be the chargeable to you.
7.2 Any additional work found to be necessary subsequent to this contract being entered into in order to obtain or comply with any statutory or other approval or consent will (if undertaken by us) be charged to you in full.

8. TITLE AND RISK
Ownership of the Goods will only pass to you when we receive payment in full of all sums due for the Goods, including delivery charges.

9. PRICE AND PAYMENT
9.1 The Price shall be the sum set out overleaf and shall be paid as follows: (a) Supply and fit: (i) a deposit of 50% of the Price payable on the acceptance of the Order; (ii) a further 50% of the Price payable on completion of the installation. (b) Supply: (i) a deposit of 50% of the Price payable as in (a) (i) above; (ii) the final 50% of the Price upon receipt of Goods. 9.2 These prices include VAT. However, if the rate of VAT changes between the date of the Order and the date of delivery, we will adjust the VAT you pay, unless you have already paid for the Goods in full before the change in the rate of VAT takes effect.
9.3 If you do not make a payment due to us by the due date for payment, we may charge interest to you on the overdue amount at the rate of 5% a year above the base rate of Allied Irish Banks (AIB). This interest shall accrue on a daily basis from the due date until the date of actual payment of the overdue amount, whether before or after judgment. You must pay us interest together with the overdue amount.
9.4 Without limiting any other remedies or rights that we may have, if you do not pay us on time, we may cancel or suspend any other outstanding Order until you have paid the outstanding amounts.
9.5 We agree to fully investigate any alleged defect notified to us by you provided we have received full payment of all sums due and payable to us by you.

10. OUR LIABILITY TO YOU
10.1 Subject to clause below, if we fail to comply with these Terms, we are only responsible for loss or damage you suffer that is a foreseeable result of our breach of the Terms or our negligence, but we are not responsible for any loss or damage that is not foreseeable. Loss or damage is foreseeable if they were an obvious consequence of our breach or if they were contemplated by you and us at the time we entered into this contract. 10.2 Our total liability to you in respect of all losses arising under or in connection with the contract shall not exceed the total amount paid by you under the contract.

11. CONSUMER RIGHTS
To cancel the contract you must inform us in writing in accordance with clause 14.

12. EVENTS OUTSIDE OUR CONTROL
12.1 We will not be liable or responsible for any failure to perform, or delay in performance of, any of our obligations under these Terms that is caused by events outside our reasonable control (a “Force Majeure Event”).
12.2 A Force Majeure Event includes any act, event, non-occurrence, omission or accident beyond our reasonable control and includes, in particular (without limitation), the following: (a) civil commotion, riot, invasion, terrorist attack or threat of terrorist attack, war (whether declared or not) or threat or preparation for war; (b) fire, explosion, inclement weather, storm, flood, earthquake, subsidence, epidemic or other natural disaster; (c) impossibility of the use of railways, shipping, aircraft, motor transport or other means of public or private transport; (d) impossibility of the use of public or private telecommunications networks; (e) the acts, decrees, legislation, regulations or restrictions of any government. (f) pandemic or epidemic. 12.3 Our obligations under these Terms are suspended for the period that the Force Majeure Event continues, and we will have an extension of time to perform these obligations for the duration of that period. We will take reasonable steps to bring the Force Majeure Event to a close or to find a solution by which our obligations under these Terms can be performed despite the Force Majeure Event.

13. TRANSFER OF RIGHTS AND OBLIGATIONS
13.1 We may transfer our rights and obligations under these Terms to another organisation, but this will not affect your rights or our obligations under these Terms.
13.2 You may not transfer your rights and obligations under these Terms to any other person.

14. NOTICES AND COMMUNICATIONS
If you wish to contact us in writing, or if any clause in these Terms requires you to give us notice in writing (for example, to cancel the contract), you can send this to us by e-mail to windows@sligoglass.com, by hand, or by post to Sligo Glass Company Ltd. at Finisklin Road, Sligo. We will confirm receipt of this by contacting you in writing. If we have to contact you or give you notice in writing, we will do so by e-mail, by hand, or by post to the address you provide to us in the Order.

15. GENERAL
15.1 If any court or competent authority decides that any of the provisions of these Terms are invalid, unlawful or unenforceable to any extent, the term will, to that extent only, be severed from the remaining terms, which will continue to be valid to the fullest extent permitted by law.
15.2 If we fail, at any time while these Terms are in force, to insist that you perform any of your obligations under these Terms, or if we do not exercise any of our rights or remedies under these Terms, that will not mean that we have waived such rights or remedies and will not mean that you do not have to comply with those obligations. If we do waive a default by you that will not mean that we will automatically waive any subsequent default by you. No waiver by us of any of these Terms shall be effective unless we expressly say that it is a waiver and we tell you so in writing.
15.3 These Terms shall be governed by Irish law and we both agree to the exclusive jurisdiction of the Irish courts.

Terms and conditions

Data protection
Your personal details will not be passed on or sold to any other company in accordance with the Data Protection Act. We may from time to time contact existing customers to inform they of a new offer or service, if you do not wish to receive these emails you may opt out at any time.

Website Terms of use
If you continue to browse and use this website, you are agreeing to comply with and be bound by the following terms and conditions of use, which together with our privacy policy govern sligo glass co ltd relationship with you in relation to this website. If you disagree with any part of these terms and conditions, please do not use our website.
The use of this website is subject to the following terms of use:
The content of the pages of this website is for your general information and use only. It is subject to change without notice.
Neither we nor any third parties provide any warranty or guarantee as to the accuracy, timeliness, performance, completeness or suitability of the information and materials found or offered on this website for any particular purpose. You acknowledge that such information and materials may contain inaccuracies or errors and we expressly exclude liability for any such inaccuracies or errors to the fullest extent permitted by law.
Your use of any information or materials on this website is entirely at your own risk, for which we shall not be liable. It shall be your own responsibility to ensure that any products, services or information available through this website meet your specific requirements.
This website contains material which is owned by or licensed to us. This material includes, but is not limited to, the design, layout, look, appearance and graphics. Reproduction is prohibited other than in accordance with the copyright notice, which forms part of these terms and conditions.
Unauthorised use of this website may give rise to a claim for damages and/or be a criminal offence. From time to time this website may also include links to other websites. These links are provided for your convenience to provide further information. They do not signify that we endorse the website(s). We have no responsibility for the content of the linked website(s).
Your use of this website and any dispute arising out of such use of the website is subject to the laws of Republic Of Ireland .

Pricing
All prices on sligoglass.com include VAT payable but delivery charges may vary. Although we endeavour to ensure that all pricing information on sligoglass.com is accurate, occasionally an error may occur and goods may be mispriced. If we discover a pricing error we will, at our discretion, either contact you and ask you whether you wish to continue with the order at the correct price or notify you that we have cancelled your order. We will not be obliged to supply goods at the incorrect price. We reserve the right to adjust prices, offers, goods and specifications of goods on sligoglass.com at our discretion at any time before (but not after) we accept your order.

Quotations
Quotations are valid for 90 Days. Quotations are a guide and extra costs may be incurred should overruns occur which are outside of our control. Extra charges for overruns shall be applied at the man hour rate of €30/hour.
Ordering Terms
Your order is accepted by us once Deposit/PO has been received. Your order may not be changed after payment is received as the manufacturing process will then begin.

Toughened Glass
You should be aware that with all toughened glass products, there is a 2mm tolerance. This is due to the toughening process itself where the glass is taken to melting point before being rapidly cooled meaning the size can change a little. If you have carefully followed our measuring instructions this should not be an issue but should your glass not fit due to this reason we cannot be held accountable.

Splashbacks
All our coloured glass splashbacks are made by back painting coloured glass so as with tiles our colours are made in batches. If you intend to place a repeat order you should be aware that there may be a colour difference, for this reason we cannot guarantee that the colour will be the same. In these circumstances you should inform us before you order that you wish to match to a previous order and we can try to work with you to do that. Please note that the colours displayed on our website are only to be used as a guide. We only use RAL Colour Chart so should you wish to be sure of the colour of the glass you will receive it is strongly advisable to​ ​order a sample​ as we cannot guarantee that our paint will match other paint manufacturers, the colour represented on an individual’s computer screen or that we can reproduce a colour to a higher than 97% level of accuracy.

Double Glazing
Seal on Double Glazing products is Guaranteed for 5 years however call-out & fitting charges for replacement glass will still apply.

Providing your own templates
Should you wish to send us your own wooden templates please do so to the address found on our about us page. We will make your glass to the exact size and shape of your templates to an accuracy of 2mm. Please note that should you choose to send us your own templates you do so at your own risk, we will not be held liable for loss or damage of your templates in the factory or be held liable for any associated costs you may have incurred in getting your templates manufactured.

Finishes, Colour additives and Named Colours
From time to time glass patterns and tints can change due to the changing manufacturing process. Some glass types can be discontinued and no longer available, in this case we will try to get closest match possible. We reserve the right to make changes to any finishes that may affect the product you receive without notice. If you have ordered a sample and you would like to make sure the sample you received will be the same finish as the end product you must inform us in case any such changes may mean we need to inform you or indeed manufacture your glass to suit it.

Distance Selling Regulations
By Paying Your Deposit/ or Sending PO you are accepting Sligo Glass Co Ltd terms & conditions.For the supply of goods made to the consumer’s own specification such as custom​ made Glass or Windows & In accordance with the distance selling regulations, orders may not be cancelled once Product has been manufactured to your specifications.

Delivery
Delivery prices quoted are for Republic of Ireland and are an estimate only.

Payment
The total cost of your order including delivery will be detailed in your invoice. Online Payment may be made using our secure online payment service.

Returns and refunds policy
Please check for any visible signs of damage to the packaging of your order before signing for the delivery. Any items damaged in transit should be noted at time of delivery, and if possible delivery should be refused and returned to us.If your Glass arrives defective this should also be noted at time of delivery and returned via the courier. If the Glass does not fit we cannot issue you a refund if the measurements match the measurements on your order, so please check your order prior to completing payment. Please ensure that you have thoroughly checked your order before signing for it. Once signed for any claims made by you will be validated at our discretion and should be raised with 24 hours of receipt. Where you have asked us to leave your order in a safe place at your premises or with a friend or neighbour you do so at your own risk. We recommend that you have the friend or neighbour check your order on your behalf. Where possible, we reserve the right to repair any defects rather than remaking that particular piece of glass or issuing any form of compensation. If the glass is fitted we are unable to consider any claims of damage. For the supply of goods made to the consumer’s own specification such as custom​ made Glass or Windows & In accordance with the distance selling regulations, orders may not be cancelled once Product has been manufactured to your specifications. No refunds can be given for Custom made Products.

This guarantee does not cover
1. Any damage accidental or deliberate occurring on site after installation and specifically excludes damage caused by cleaning practices or application of any chemicals or abrasive substances.
2. Any damage caused by other operations in the build process and specifically excludes damage by cement, mortar, render or any cleaning operation to remove these substances.
3. Failure of hinges due to the build up of cement, mortar, sand, grit or any other building debris in the moving parts.
4. Failure of moving parts due to lack of lubrication.
5. Corrosion or discolouration of ironmongery caused by cleaning agents, chemicals or dirty water from cleaning operations.
6. Faults on products which have not been maintained according to maintenance guidelines. The end user of this guarantee is responsible for cleaning and maintenance of these products.
7. Visual defects in glass, such as scratches or marks which are not reported within 48 hours of installation. Such defects must be assessed according to the GGF Visual Quality Standards.
8. Any visual defects in the product that are not reported within three days of installation in writing.
9. Any damaged caused by condensation being deposited on windows and doors. Condensation is an indication of excess moisture in the building and is not a window problem.
10. Redecoration of items or components which have been replaced or their surroundings.
11.Any product which has not been paid for in full.

Account Holders
Accounts not paid within 30 days are subject to late payment fees in accordance with Commercial Transaction Regulations 2001 (SI 388 OF 2002) Disclaimer: Title of Goods does not pass until payment is received in full. Shortages, Damaged or Receipt of Incorrect Goods must be reported immediately.